Terms & Conditions
Effective Date: 19th August, 2025
Welcome to Doors Connect. By accessing or using our website and services, you agree to comply with the following Terms & Conditions. Please read them carefully before engaging with our services.
General Information
- This website is owned and operated by Doors Connect.
- All content, including text, images, and materials, is for general information about our construction, renovation, and maintenance services.
- We reserve the right to update or modify these Terms & Conditions at any time without prior notice.
Services
- We provide renovation, repair, maintenance, and construction-related services as described on our website.
- All service bookings, estimates, and project timelines will be confirmed in writing through email or contract agreements.
- Prices and quotations are subject to change based on site inspections, material availability, or client requirements.
Use of Website
- You agree not to misuse our website by uploading harmful content, attempting unauthorized access, or misrepresenting your identity.
- Any information you provide through forms (contact, booking, quotation requests) must be accurate and truthful.
Payments & Billing
- Payments for services must be made as per the agreed quotation or contract.
- Deposits may be required before work begins, with the balance payable upon project milestones or completion.
- Late payments may result in delays or suspension of work or even include legal actions.
Warranties & Liabilities
- While we strive for quality and timely completion, project timelines may be affected by external factors (e.g., weather, supply chain delays, regulatory approvals).
- We are not liable for damages arising from misuse of our services, delays caused by third parties, or unforeseen circumstances beyond our control.
- Any warranties or guarantees will be specified in the service contract.
Third-Party Links & Services
Our website may include links to third-party sites (e.g., material suppliers, contractors). We are not responsible for the content or policies of those websites.
Intellectual Property
All website content (text, designs, images, and logos) is the property of Doors Connect and cannot be copied or reused without permission.
Governing Law
- These Terms & Conditions are governed by the laws of Nepal.
- Any disputes will be handled in the courts of the relevant jurisdiction.
Contact Us
If you have any questions about our Cookie Policy, please contact us at:
Email Id: admin@doorsconnect.com.np
Phone Number: 9801973135
Book Through Our Website & Enjoy 5% Off All Services!
Experience hassle-free home renovation and maintenance. Explore our expert services, personalized solutions, and timely delivery.
- Copyright © 2025 Doors Connect | All Rights Reserved.